Concurrent delay: everything to play for

Aidan Steensma is Of Counsel for infrastructure, construction and energy disputes at CMS London Concurrent delay is a favourite topic of construction lawyers, with a wide variety of views being held and a scarcity of authoritative guidance from the courts. A decision of the Technology… The post Concurrent delay: everything to play for appeared first on Construction News.

Delay Case Law - Thomas Barnes & Sons V Blackburn November 2022

A RAY OF LIGHT CAST OVER THE ‘DARK ART’: A publication from Beale & Co solicitors considering Delay Analysis arising from Thomas Barnes & Sons plc V Blackburn with Darwin Borough Council

Concurrent Delays

In their September edition of Outlaw Pinsent Masons provide a nice summary of case law and the competing legal positions existing on the topic of concurrent delay.

Silver Shemmings Ash - What is Concurrent Delay (Part 2), 10042020

A further seminar on the topic of Concurrent Delay, this time presented by Henry Hathaway

Paul Whatley - Concurrent Delay in Construction 19052017

Presentation by Paul Whatley about Concurrent Delay in Construction covering: Construction Planning; Progress measurement, Earned Value Analysis, and Delay Analysis

Silver Shemmings Ash - What is Concurrent Delay

Mohammed Haque discusses Concurrent Delay, answering some frequently asked questions including what is concurrent delay and how do the Courts treat it?

Is it time that the JCT and/or NEC enable the parties to set out the methodology of Delay Analysis and how to deal with Concurrent Delay?

Is it rare for concurrent delay to occur on construction projects?

CDI EXPERTS PTY LTD

CDI Experts is an independent, privately owned, multi-disciplinary service provider specializing in contract, commercial, project controls, and dispute resolution solutions for our clients in the Natural Resources, Infrastructure, and Property sectors. CDI Experts are quality driven, cost effective and time proficient in meeting the needs of our clients. We assist in managing our client’s project risk from the tender stage through project execution and closeout to resolution of any potential disputes.